Agenda - Council - 08/23/2016 - Laserfiche WebLink

Home

12.02 Change of Contract Times entitled to an equitable adjustment in Contract Times, if such adjustment is essential to A. The Contract Times may only be changed by Contractor's ability to complete the Work a Change Order.Any Claim for an adjustment within the Contract Times. Such an in the Contract Times shall be based on adjustment shall be Contractor's sole and written notice submitted by the party making exclusive remedy for the delays described in the Claim to the Engineer and the other party this Paragraph 12.03.C. to the Contract in accordance with the provisions of Paragraph 10.05. D. Owner, Engineer and the Related Entities of each of them shall not be liable to Contractor B. Any adjustment of the Contract Times for any claims, costs, losses, or damages covered by a Change Order or any Claim for (including but not limited to all fees and an adjustment in the Contract Times will be charges of Engineers, architects, attorneys, determined in accordance with the provisions and other professionals and all court or of this Article 12. arbitration or other dispute resolution costs) sustained by Contractor on or in connection 12.03 Delays with any other project or anticipated project. A. Where Contractor is prevented from E. Contractor shall not be entitled to an completing any part of the Work within the adjustment in Contract Price or Contract Contract Times due to delay beyond the Times for delays within the control of control of Contractor,the Contract Times will Contractor. Delays attributable to and within be extended in an amount equal to the time the control of a Subcontractor or Supplier lost due to such delay if a Claim is made shall be deemed to be delays within the therefor as provided in Paragraph 12.02.A. control of Contractor. Delays beyond the control of Contractor shall include, but not be limited to, acts or neglect ARTICLE 13—TESTS AND INSPECTIONS; by Owner,acts or neglect of utility owners or CORRECTION,REMOVAL OR ACCEPTANCE OF other contractors performing other work as DEFECTIVE WORK contemplated by Article 7, fires, floods, epidemics, abnormal weather conditions, or 13.01 Notice of Defects acts of God. A. Prompt notice of all defective Work of which B. If Owner, Engineer, or other contractors or Owner or Engineer has actual knowledge will utility owners performing other work for be given to Contractor. All defective Work Owner as contemplated by Article 7, or may be rejected, corrected, or accepted as anyone for whom Owner is responsible, provided in this Article 13. delays, disrupts, or interferes with the performance or progress of the Work, then 13.02 Access to Work Contractor shall be entitled to an equitable adjustment in the Contract Price or the A. Owner, Engineer, their consultants and other Contract Times, or both. Contractor's representatives and personnel of Owner, entitlement to an adjustment of the Contract independent testing laboratories, and Times is conditioned on such adjustment governmental agencies with jurisdictional being essential to Contractor's ability to interests will have access to the Site and the complete the Work within the Contract Work at reasonable times for their Times. observation, inspecting, and testing. Contractor shall provide them proper and safe C. If Contractor is delayed in the performance or conditions for such access and advise them of progress of the Work by fire,flood,epidemic, Contractor's Site safety procedures and abnormal weather conditions, acts of God, programs so that they may comply therewith acts or failures to act of utility owners not as applicable. under the control of Owner, or other causes not the fault of and beyond control of Owner and Contractor, then Contractor shall be Standard General Conditions 00 72 00-37