Agenda - Council - 06/27/2017 - Laserfiche WebLink

Home

D. If Contractor damages, delays, disrupts, or interferes with the work of any other contractor, or any utility owner performing other work at or adjacent to the Site, through Contractor's failure to take reasonable and customary measures to avoid such impacts, or if any claim arising out of Contractor's actions, inactions, or negligence in performance of the Work at or adjacent to the Site is made by any such other contractor or utility owner against Contractor, Owner, or Engineer, then Contractor shall (1) promptly attempt to settle the claim as to all parties through negotiations with such other contractor or utility owner, or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law, and (2) indemnify and hold harmless Owner and Engineer, and the officers, directors, members, partners, employees, agents, consultants and subcontractors of each and any of them from and against any such claims, and against all costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such damage, delay, disruption, or interference. ARTICLE 9 — OWNER'S RESPONSIBILITIES 9.01 Communications to Contractor A. Except as otherwise provided in these General Conditions, Owner shall issue all communications to Contractor through Engineer. 9.02 Replacement of Engineer A. Owner may at its discretion appoint an engineer to replace Engineer, provided Contractor makes no reasonable objection to the replacement engineer. The replacement engineer's status under the Contract Documents shall be that of the former Engineer. 9.03 Furnish Data A. Owner shall promptly furnish the data required of Owner under the Contract Documents. 9.04 Pay When Due A. Owner shall make payments to Contractor when they are due as provided in the Agreement. 9.05 Lands and Easements; Reports, Tests, and Drawings A. Owner's duties with respect to providing lands and easements are set forth in Paragraph 5.01. B. Owner's duties with respect to providing engineering surveys to establish reference points are set forth in Paragraph 4.03. C. Article 5 refers to Owner's identifying and making available to Contractor copies of reports of explorations and tests of conditions at the Site, and drawings of physical conditions relating to existing surface or subsurface structures at the Site. 9.06 Insurance A. Owner's responsibilities, if any, with respect to purchasing and maintaining liability and property insurance are set forth in Article 6. 9.07 Change Orders A. Owner's responsibilities with respect to Change Orders are set forth in Article 11. EJCDC® C-700, Standard General Conditions of the Construction Contract. Copyright © 2013 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved. Page 40 of 65