Agenda - Council - 10/14/2025 - Laserfiche WebLink

Home

and all documents attached hereto, are true, correct and complete. 2. **Payroll Records and Final Payment**. **If this Certification is submitted to receive full and final payment on the Project, Subcontractor represents and warrants to General Contractor that attached to this Certification as Exhibit are the following, each of which is true, complete and correct as of the date hereof ** 1. A full and complete list of all employees and independent contractors of Subcontractor who performed work for the benefit of the Project during the Certification Period (each such employee and independent, whether or not identified on Exhibit A, is referred to herein as a "Service Provider'), including, with respect to each such Service Provider: (i) full name; (ii) home address and telephone number; (iii) date of hire; (iv) current rate of pay; (v) status and employee or independent contractor; (vi) status as a full- time or part-time employee; (vii) status as an exempt or non-exempt employee; (viii) title of employment; and (ix) general description of work performed at the Project. 2. Full payroll and payment records of Subcontractor with respect to each Service Provider, including written evidence of all wages, fringe benefit contributions, and other compensation delivered by Subcontractor to the Subject Employees with respect to the Certification Period. 3. **Additional Agreements * *. 1. This Certification is being signed and submitted, for the purpose of and as a condition to Subcontractor's receipt of payment fbr services and labor perforied in connection with the Project and Subcontractor acknowledges and agrees that without Subcontractor's delivery of this Certification to the General Contractor, 2. Subcontractor agrees that in the event any employee of independent contractor of General Contractor, Project Owner, or any affiliate of General Contractor or Project Owner is entitled to and may offset against amounts otherwise due and payable to General Contractor any and all losses incurred or anticipated to be incur General Contractor paid to a claimant or a third party acting on behalf of a claimant resulting from the actions or inactions of Subcontractor acting under, by, or for General Contractor, including all unpaid wages, fringe benefits, penalties, and resulting liquidated damages. 3. To the fullest extent permitted by applicable law, Subcontractor waives and releases any and all rights of mechanic's liens, inateriahnen's lien, laborer's lien, and similar rights for payment for services and labor performed by Subcontractor under the Project. 4. Subcontractor will indemnify, defend and hold harmless General Contractor and its shareholders, officers, directors, employees, agents, insurers, affiliates, successors and assigns from and against all liability, loss, harm, damage, costs, and expenses (including attorneys' fees) arising out of based upon, or related to this Certification. For the avoidance of doubt, the title owner of the real property on which the Project is located is an intended third party beneficiary of the terms of this Certification. • **PLEASE PROVIDE IN EXHIBIT A:** o A. A full and complete list of all employees and independent contractors of Subcontractor who performed work for the benefit of the Project during the Certification Period (each such employee and independent, whether or not identified